Estudios de caso
J.S. Held fortalece su experiencia en contabilidad forense para litigios matrimoniales y comerciales con la adquisición de Forensic Accountants & Consultants.
LEER MÁSJ.S. Held was engaged to provide advisory support for a large-scale pipeline infrastructure project spanning several hundred kilometers across multiple regions. The project involved installation of the mainline pipeline, construction of associated valve and facility connections, hydrostatic testing and commissioning activities, management of stockpile and staging areas, development of temporary and permanent access infrastructure, and environmental restoration and rehabilitation of disturbed areas.
The contractor was responsible for delivering the project in accordance with contractual requirements related to schedule, budget, safety, quality, and reporting obligations. The owner was responsible for providing certain materials, engineering information, permits, approvals, and right-of-way access.
Project execution required robust scheduling, cost control, risk and change management, and integrated reporting systems.
During construction, the project encountered numerous challenges that adversely affected productivity, work sequencing, and overall schedule performance. These issues included permitting and access constraints, environmental and wildlife restrictions, complex site conditions, public health and workforce limitations, and other operational inefficiencies.
As a result, the project became the subject of a dispute concerning responsibility for schedule delays, productivity impacts, and significant additional costs incurred during execution.
J.S. Held provided independent construction advisory and expert consulting services to evaluate schedule delays, project management performance, cost impacts, and damages associated with the project.
Our team performed detailed analyses of delay causation, critical path impacts, project controls performance, cost management practices, change management procedures, productivity losses, and alleged additional costs and damages.
Our review assessed project management performance against contractual obligations, industry best practices, and recognized project controls standards across schedule management, cost control, integration management, and risk management disciplines.
> Construction Dispute Resolution & International Arbitration
Nuestros expertos brindan apoyo a clientes en la resolución de problemas financieros, técnicos y contractuales que pueden surgir en los proyectos de ingeniería y construcción, a través de todas las formas de resolución de conflictos. Brindamos apoyo en arbitrajes, litigios y mediaciones relacionados con la construcción, aprovechando la experiencia profunda en la industria, análisis claro y un entendimiento profundo de los proyectos de construcción globales. Nuestros expertos aportan conocimientos técnicos desde la fase inicial de descubrimiento hasta la resolución final, ayudando a los clientes a superar desafíos como conflictos contractuales, retrasos en los proyectos, impactos en los costos de los proyectos y defectos de calidad, entre otros asuntos.
> Servicios de asesoramiento y reclamaciones de contratos de construcción
Los expertos en reclamos de construcción de J.S. Held apoyan a profesionales de la construcción para identificar y evaluar riesgos, y evitar y resolver conflictos relacionados con el proyecto. Proveemos análisis independientes y objetivos en asuntos complejos relacionados con la construcción, basados en años de experiencia técnica y conocimiento de la industria.
For additional information about the engagement or to learn more about our services, contact:
